Terms of Service – Infinity Art & Frames UAE
Welcome to Infinity Art & Frames UAE. These Terms of Service govern your access to and use of our website, products, and services related to custom picture framing, glass works, mirror installations, and art solutions in Dubai, United Arab Emirates. By engaging with our services or accessing our website, you agree to be bound by these terms.
Acceptance of Terms
By using our services, requesting a quotation, or placing an order, you acknowledge that you have read, understood, and agreed to these Terms of Service. If you do not agree, you should not use our services.
Services Overview
Infinity Art & Frames UAE provides customized framing, glass, mirror, and art-related services tailored to client requirements. All services are subject to availability, technical feasibility, and approval of design specifications.
Quotations & Pricing
All quotations provided are based on project requirements, materials, dimensions, and customization. Prices may vary depending on changes in scope or specifications. We reserve the right to revise pricing prior to final confirmation.
Order Confirmation
Orders are considered confirmed only after mutual agreement on design, specifications, timelines, and payment terms. Once an order is confirmed, modifications may not be possible or may incur additional charges.
Payments
Payments must be made as agreed during the order confirmation process. Partial or full advance payments may be required before initiating work. Failure to complete payments may result in delays or cancellation of services.
Production & Delivery
We strive to complete all projects within agreed timelines. However, delays may occur due to material availability, design complexity, logistics, or unforeseen circumstances. Infinity Art & Frames UAE shall not be held liable for such delays.
Cancellation Policy
Orders may be canceled only before production has commenced. Once production or customization has started, cancellations are not permitted due to the personalized nature of our services.
Refund Policy
All confirmed and initiated service orders are non-refundable. Refunds, if applicable, will be handled in accordance with our Refund Policy and only in exceptional circumstances.
Customer Responsibilities
Customers are responsible for providing accurate information, measurements, and design approvals. Infinity Art & Frames UAE is not liable for issues arising from incorrect or incomplete information provided by the customer.
Intellectual Property
All website content, designs, images, and materials are the intellectual property of Infinity Art & Frames UAE and are protected under applicable laws. Unauthorized use, reproduction, or distribution is strictly prohibited.
Limitation of Liability
Infinity Art & Frames UAE shall not be liable for any indirect, incidental, or consequential damages arising from the use of our services. Our total liability shall not exceed the value of the service provided.
Third-Party Services
We may use third-party vendors or partners for certain aspects of service delivery. While we ensure quality standards, we are not responsible for delays or issues caused by third-party services.
Governing Law
These Terms of Service shall be governed and interpreted in accordance with the laws of the United Arab Emirates. Any disputes shall be subject to the jurisdiction of the courts of Dubai.
Changes to Terms
Infinity Art & Frames UAE reserves the right to update or modify these Terms of Service at any time. Continued use of our services constitutes acceptance of the revised terms.
Contact Information
If you have any questions regarding these Terms of Service, please contact us:
Infinity Art & Frames UAE
Workshop Address:
Al Quoz Industrial Area 3rd, Plot No. 368-419, 3G-1
Dubai, United Arab Emirates
Registered Office Address:
PROPERTY INVESTMENT OFFICE 4 - S1
Dubai Investment Park First
Dubai, United Arab Emirates
Email: